Home Improvement Contract

---

This Home Improvement Contract ("Contract") is entered into as of May 25, 2055, by and between [Your Name], an independent contractor with a main business address at [Your Company Address] ("Contractor"), and [Homeowner Name], with an address at [Homeowner Address] (the "Homeowner") (collectively known as the "Parties").

1. Project Description

This Home Improvement Contract outlines the terms and conditions for renovation and remodeling work to be performed at the specified property. The project includes a comprehensive renovation of the kitchen, the addition of a new bathroom, and the conversion of the basement into a functional living space.

Scope of Work:

• Kitchen Renovation: Installation of new cabinetry, countertops, backsplash, and state-of-the-art kitchen appliances.

• Bathroom Addition: Construction of a new full bathroom, encompassing all necessary plumbing, fixtures, tiling, and electrical work.

• Basement Conversion: Transformation of the basement into a comfortable living area, including but not limited to insulation, drywall installation, electrical wiring, and flooring.

2. Project Timeline

Start Date: May 25, 2055
Estimated Completion Date: August 30, 2055

Work on the project shall begin no later than the specified Start Date and will be pursued diligently toward completion, aiming for the Estimated Completion Date, subject to any reasonable delays.

3. Payment Schedule

The agreed-upon total cost for the completion of the project is $45,000. Payments are to be made as follows:

• Deposit: $9,000 due upon signing of this contract.

• Progress Payment #1: $12,000 due on June 15, 2055.

• Progress Payment #2: $12,000 due on July 20, 2055.

• Final Payment: $12,000, due upon completion and final inspection of the project, ensuring satisfaction.

4. Specifications and Materials

Materials for the project will be of standard quality or as mutually agreed upon. Selections for finishes, fixtures, and materials will be made from options provided by the Contractor. Changes to materials or design may adjust project costs accordingly.

5. Changes to the Work

Any changes to the original scope of work will require a written Change Order, detailing the change, adjusted costs, and any effect on the project timeline. Change Orders must be agreed upon and signed by both parties before implementation.

6. Warranties and Guarantees

The Contractor guarantees work to be free from defects in workmanship and materials for one (1) year from the date of completion. This warranty covers labor and materials for repairs within the warranty period.

7. Dispute Resolution

Disputes arising under this contract shall first be attempted to be resolved through direct negotiation. If unresolved, mediation or arbitration may be sought as agreed upon by both parties, before any legal action.

8. Termination

This contract may be terminated by either party with written notice if there is a substantial breach of terms that is not rectified within thirty (30) days of notice of such breach.

---

Signature

The parties hereby agree to the terms and conditions outlined in this Home Improvement Contract and by their signatures below commit to their adherence.

Contractor:

Name: [Your Name]
Date: [Date]

Homeowner:

Name: [Homeowner's Name]
Date: [Date]

Contract Templates @ Template.net