Interior Design Contract

---

This Interior Design Contract dated [DATE], is made BETWEEN [CLIENT'S NAME], of [CLIENT'S COMPANY ADDRESS] (hereinafter referred to as "Client") and [YOUR COMPANY NAME] of [YOUR COMPANY ADDRESS] (hereinafter referred to as "Designer").

1. Parties

This contract ("Contract") is entered into as of [Date], by and between:

Client's Information:
Client's Full Name: [CLIENT'S NAME],
Client's Address: [CLIENT'S ADDRESS],
Client's Contact Information:

Interior Designer:
Designer's Full Name: [Your Name]
Designer's Address: [Your Address]
Designer's Contact Information: [Your Email]

2. Scope of Work

This section outlines the specific services the interior designer will provide, including but not limited to:

2.1 Initial Consultation:

• Gather client requirements and budget constraints.

2.2 Concept Development:

• Create design ideas and present them for client feedback.

2.3 Space Planning:

• Optimize functionality and flow of interior space.

2.4 Material Selection:

• Assist in choosing materials, finishes, and colors.

2.5 Procurement:

• Source and procure furniture, accessories, and fixtures.

2.6 Installation Oversight:

• Ensure correct implementation of design elements.

2.7 Project Management:

• Manage timelines, budgets, and communication.

3. Schedule

This section specifies the timeline for completion of various phases of the project, including:

Milestones:

1. Concept Development: Begin brainstorming and conceptualizing interior design ideas.

2. Client Consultation: Conduct initial meetings with the client to understand their requirements and preferences.

3. Preliminary Design Proposal: Present initial design concepts and receive feedback from the client.

4. Design Refinement: Incorporate client feedback and make necessary adjustments to the design.

5. Final Design Approval: Obtain final approval from the client on the interior design proposal.

6. Procurement: Source materials, furniture, and decor items as per the finalized design plan.

7. Implementation: Oversee the execution of the design plan, including coordination with contractors and vendors.

8. Final Inspection: Conduct a thorough inspection of the completed interior design project to ensure it meets quality standards and client expectations.

Completion Date: [Insert Completion Date]

4. Payment Terms

This section details the financial arrangement between the client and the interior designer, including:

• Total Project Cost: [amount]

• Payment Schedule:

  • Deposit: [percentage]% upon signing.

  • Progress Payments: At project milestones.

  • Final Payment: Upon completion and client approval.

• Payment Methods: [accepted methods].

• Late Payment Penalties: [penalty details].

5. Client Responsibilities

This section outlines the responsibilities of the client specific to the interior design contract, which may include:

• Providing necessary information and approvals promptly related to the interior design project, such as preferences, specifications, and any changes requested.

• Granting access to the premises where the interior design work will take place, ensuring that designers and contractors have sufficient access to the designated areas.

• Ensuring compliance with building codes and regulations pertinent to the interior design project, including obtaining necessary permits or permissions.

• Payment of fees according to the agreed terms outlined in the interior design contract, including any deposits, progress payments, or final payments as specified in the agreement.

6. Designer Responsibilities

This section outlines the responsibilities of the interior designer, including:

• Providing design services in a professional manner

• Complying with applicable laws and regulations

• Meeting project deadlines

• Communicating with the client regularly

7. Changes and Additional Work

Changes to the scope of work in the interior design contract will be handled as follows:

7.1 Requesting Changes:

Clients or the interior design firm must submit change requests in writing, explaining the proposed modifications.

7.2 Impact Assessment:

The firm will promptly assess how changes affect the project timeline and cost, considering factors like materials, labor, and design adjustments.

7.3 Written Agreement:

Both parties must agree to changes in writing, detailing the modifications, revised timeline, and cost adjustments.

8. Termination

This section outlines the conditions under which the contract may be terminated by either party, including:

8.1 Breach:

Either party may terminate upon written notice if the other breaches the contract, with an opportunity for remedy.

8.2 Failure to Perform:

The contract may be terminated if either party fails to fulfill obligations, with reasonable notice for rectification.

8.3 Mutual Agreement:

Both parties can mutually terminate the contract by a written agreement, settling outstanding obligations.

9. Dispute Resolution

This section specifies the procedure for resolving disputes that may arise during the project, including:

• Negotiation: Parties discuss to find a compromise.

• Mediation: A neutral third party helps find a solution.

• Arbitration: Impartial arbitrators make legally binding decisions.

• Litigation: Legal proceedings through the court system, as a last resort.

10. Governing Law

This contract is governed by the laws of [STATE]. Any disputes will be resolved in the courts of [COUNTRY], [STATE]."

11. Entire Agreement

This Interior Design Contract constitutes the entire agreement between [CLIENT'S NAME] and [DESIGNER'S NAME] and supersedes any prior agreements, understandings, or negotiations, whether written or oral, relating to the subject matter herein. Any modifications or amendments to this Contract must be made in writing and signed by both parties. No other representations, warranties, or promises not expressly contained herein shall be binding upon the parties.

12. Signatures

This section contains spaces for the signatures of both parties, indicating their acceptance of the terms and conditions outlined in the contract.

[CLIENT'S NAME]

[CLIENT'S COMPANY NAME]

[DATE]

[YOUR NAME]

[YOUR COMPANY NAME]

[DATE]

Contract Templates @ Template.net