JCT Contract
JCT CONTRACT
This contract ("Contract") from here forward is entered into as of [Date], by and between [Contractor Name], henceforth referred to as "Contractor," with an address at 2471 Lodgeville Road Minneapolis, MN 55402, and [Client Name], henceforth referred to as "Client," with an address at 65 Lowes Alley Columbus, OH 43201.
1. Scope of Work
1.1 The Contractor agrees to perform the following services ("Services"):
-
Detailed description of the project or task to be completed.
-
Specific deliverables, milestones, or timelines, if applicable.
2. Payment Terms
2.1 The Client agrees to compensate the Contractor for the Services provided according to the following terms:
-
Total project cost: [Total Amount].
-
Payment schedule: [Specify milestone payments, progress payments, or other payment terms].
-
Method of payment: [Specify preferred payment method, such as bank transfer, check, etc.].
3. Duration and Schedule
3.1 The Parties agree upon the following timeline for the completion of the Services:
-
Commencement Date: [Start Date].
-
Completion Date: [End Date].
-
Working hours: [Specify working hours, including any overtime provisions].
4. Responsibilities
4.1 Contractor's Responsibilities:
-
Provide skilled labor, materials, and equipment necessary for the completion of the Services.
-
Ensure all work is performed under industry standards and applicable regulations.
-
Maintain a safe working environment for all personnel involved in the project.
4.2 Client's Responsibilities:
-
Provide necessary access to the project site and utilities required for the completion of the Services.
-
Cooperate with the Contractor and provide timely decisions or approvals as necessary.
-
Promptly notify the Contractor of any changes or concerns regarding the project.
5. Change Orders
Any changes to the scope of work must be agreed upon in writing by both Parties through a formal change order process. The change order shall outline the modifications to the Services, the associated costs, and any adjustments to the project timeline.
6. Termination
Either Party may terminate this Contract upon written notice to the other Party in the event of a material breach of the terms herein, subject to any applicable cure period.
7. Dispute Resolution
Any disputes arising out of or relating to this Contract shall be resolved through good faith negotiations between the Parties. If a resolution cannot be reached, the Parties agree to pursue mediation or arbitration following [Specify governing law and jurisdiction].
8. Governing Law
This Contract shall be governed by and construed by the laws of [Specify governing jurisdiction].
9. Entire Agreement
This Contract constitutes the entire agreement between the Parties concerning the subject matter herein and supersedes all prior agreements, understandings, and negotiations, whether written or oral.
10. Signatures
The Parties hereby acknowledge their understanding and acceptance of the terms and conditions set forth herein by signing below:
[Contractor’s Full Name]
[Date Signed]
[Client’s Full Name]
[Date Signed]
