Defense Procurement Contract

This Defense Procurement Contract ("Contract") is entered into as of this [Month Day, Year] (the "Effective Date") by and between:

[Your Company Name], a corporation organized and existing under the laws of the United States, with its principal office located at [Your Company Address] ("Contractor"),

AND

[U.S. Government Agency or Department Name], an agency of the United States Government, with its principal office located at [U.S. Government Agency Address] ("Government").

Recitals

WHEREAS, the Government requires certain goods and services related to defense procurement as outlined in this Contract;

WHEREAS, the Contractor possesses the expertise, capacity, and resources to provide the required goods and services to meet the Government's needs; and

WHEREAS, the Government desires to procure such goods and services from the Contractor under the terms and conditions set forth in this Contract.

NOW, THEREFORE, in consideration of the mutual promises and covenants contained herein, the parties agree as follows:

Article I – Definitions

For the purposes of this Contract, the following terms shall have the meanings set forth below:

"Deliverables" means the products, materials, and services to be provided by the Contractor as specified in [Exhibit A].

"Specifications" means the technical, functional, and performance requirements for the Deliverables as set forth in [Exhibit B].

"Completion Date" means the date by which all Deliverables must be provided to the Government in accordance with the terms of this Contract.

"Contract Price" means the total price the Government agrees to pay for the Deliverables, as outlined in [Exhibit C].

"Force Majeure" means an event or circumstance beyond the reasonable control of either party, including but not limited to war, natural disasters, strikes, and changes in law or regulations.

Article II – Scope of Work

• Contractor Obligations: The Contractor agrees to deliver the goods and services described in [Exhibit A] ("Statement of Work") in accordance with the Specifications outlined in [Exhibit B].

• Specifications and Changes: The Deliverables shall be subject to the Specifications as outlined in Exhibit B. The Contractor must obtain the Government’s written approval for any modifications or deviations from the Specifications.

• Quality Assurance: The Contractor shall implement quality assurance procedures to ensure that all Deliverables meet the performance and quality standards described in this Contract.

Article III – Period of Performance

• Effective Date: This Contract shall be effective as of the Effective Date.

• Completion Date: The Contractor agrees to deliver the Deliverables by [Month Day, Year] or such later date as may be mutually agreed upon in writing by both parties.

• Extension of Time: If the Contractor is unable to meet the Completion Date due to Force Majeure or other agreed-upon circumstances, the Government may grant an extension of time.

Article IV – Payment Terms

1. Contract Price: The Government agrees to pay the Contractor the Contract Price specified in [Exhibit C] for the full and satisfactory completion of the Deliverables.

2. Payment Schedule: Payments shall be made in installments as follows:

• [0]% upon the execution of this Contract.

• [0]% upon completion of the first phase, including hardware and software prototyping and successful initial testing.

• [0]% upon final acceptance of all Deliverables.

Payments will be made upon submission of invoices by the Contractor, and the Government shall process these invoices within [0] days from receipt.

3. Invoices: The Contractor shall submit invoices to [Government Department Name] at [Government Department Address], detailing the work completed and the amount due.

4. Late Payments: If the Government fails to make any payment within the prescribed period, the Contractor may charge interest at a rate of [0]% per month on the overdue amount.

Article V – Contractor's Representations and Warranties

The Contractor represents and warrants that:

• Authority: The Contractor has the full legal authority to enter into and perform this Contract.

• Compliance with Laws: The Contractor shall comply with all applicable federal, state, and local laws, regulations, and directives, including the Federal Acquisition Regulation (FAR) and Defense Federal Acquisition Regulation Supplement (DFARS).

• No Conflicts of Interest: The Contractor affirms that there are no conflicts of interest that could affect its ability to perform under this Contract.

• Quality Assurance: The Contractor guarantees that all goods and services provided under this Contract will meet or exceed the Specifications outlined in [Exhibit B].

Article VI – Government's Responsibilities

The Government agrees to:

• Provide Timely Feedback: The Government shall provide the Contractor with timely feedback and approvals as required under this Contract to ensure the Deliverables are completed on time.

• Access to Information: The Government will provide the Contractor with access to any necessary information and resources that are needed to perform the work described in this Contract.

• Payment for Work: The Government agrees to pay the Contractor for work performed in accordance with the terms and conditions outlined in Article IV.

Article VII – Confidentiality and Security

• Confidentiality: The Contractor agrees to keep all confidential and proprietary information received from the Government during the term of this Contract confidential and not to disclose such information without the prior written consent of the Government.

• Security Requirements: The Contractor shall comply with all applicable security standards and requirements established by the U.S. Department of Defense (DoD) and other relevant authorities for handling classified or sensitive information.

Article VIII – Termination

• Termination for Convenience: The Government may terminate this Contract, in whole or in part, for its convenience by providing written notice to the Contractor. In the event of termination for convenience, the Government shall pay the Contractor for work completed up to the date of termination.

• Termination for Cause: The Government may terminate this Contract for cause if the Contractor fails to perform any material obligation under this Contract, including failure to meet the Specifications or the Completion Date. In the event of termination for cause, the Government may pursue any available remedies under the law.

• Termination for Default: The Contractor may terminate this Contract if the Government fails to fulfill its obligations under the Contract within [Number] days after written notice from the Contractor.

Article IX – Dispute Resolution

• Negotiation: The parties agree to make a good-faith effort to resolve any disputes arising out of or relating to this Contract through direct negotiations.

• Arbitration: If the parties cannot resolve the dispute through negotiation, the dispute shall be resolved by binding arbitration in accordance with the rules of the American Arbitration Association (AAA).

Article X – Miscellaneous

• Governing Law: This Contract shall be governed by and construed in accordance with the laws of the United States of America.

• Force Majeure: Neither party shall be held liable for any failure to perform its obligations due to an event of Force Majeure.

• Assignment: The Contractor may not assign or transfer any of its rights or obligations under this Contract without the prior written consent of the Government.

• Entire Agreement: This Contract, together with all exhibits and attachments, constitutes the entire agreement between the parties and supersedes all prior agreements or understandings.

IN WITNESS WHEREOF, the parties hereto have caused this Contract to be executed as of the Effective Date.

[Your Company Name]

By:

[Your Name]

[Title]

[Month Day, Year]

[U.S. Government Agency Name]

By:

[Full Name]

[Title]

[Month Day, Year]

Defense Templates @ Template.net