Interior Design Residential Contract
I. Introduction
A. Parties Involved
Client: [Client Name]
-
Address: [Client Address]
-
Email: [Client Email]
-
Phone Number: [Client Phone Number]
Designer: [Your Company Name]
-
Address: [Your Company Address]
-
Email: [Your Company Email]
-
Phone Number: [Your Company Phone Number]
-
Website: [Your Company Website]
II. Scope of Work
A. Services Provided
-
Initial Consultation and Assessment
-
Designer will conduct an initial consultation with the Client to discuss design preferences, requirements, and budget. This consultation will involve a thorough discussion to understand the Client's vision for the space, including preferred design styles, color schemes, functional needs, and any specific requirements or constraints.
-
Following the consultation, Designer will assess the residential property to determine design feasibility and potential challenges. This assessment will include evaluating the existing layout, architectural features, and any limitations that may impact the design process.
-
-
Design Concept Development
-
Designer will develop design concepts and mood boards based on the Client's preferences and input gathered during the initial consultation. These concepts will encompass various elements such as furniture selection, lighting design, material choices, and decorative accents, presented in a visually engaging format to help the Client visualize the proposed design direction.
-
Client will have the opportunity to review and provide feedback on the design concepts before finalization. Designer will collaborate closely with the Client to incorporate any requested revisions or adjustments to ensure that the final design aligns with the Client's vision and expectations.
-
III. Project Timeline
A. Start Date
-
The project is scheduled to commence on June 1, 2050. This start date marks the beginning of the interior design process, including initial consultations, site assessments, and preliminary planning.
B. Completion Date
-
The project is expected to be completed by September 1, 2050. This completion date signifies the culmination of all design activities, including concept development, procurement, installation, and final walkthroughs.
-
Phased Timeline
-
Phase 1 (June 1 - June 15, 2050): Initial Consultation and Assessment
-
Designer will conduct an in-depth consultation with the Client to gather requirements and preferences.
-
Site assessments and measurements will be performed to evaluate the property's layout and features.
-
-
Phase 2 (June 16 - July 15, 2050): Design Concept Development
-
Designer will develop initial design concepts and mood boards based on the Client's input.
-
Client feedback and revisions will be incorporated to refine the design direction.
-
-
Phase 3 (July 16 - August 15, 2050): Procurement and Execution
-
Designer will finalize design plans and initiate procurement of furniture, fixtures, and equipment (FF&E).
-
Contractors and vendors will be engaged for implementation and installation as per the approved design.
-
-
Phase 4 (August 16 - September 1, 2050): Finalization and Handover
-
Final walkthroughs will be conducted to ensure all aspects of the design are executed according to specifications.
-
Client will be presented with the completed project and any necessary documentation.
-
-
IV. Payment Terms
A. Total Cost
-
The total cost for the interior design services outlined in this contract is [$15,000]. This comprehensive fee covers all design-related activities, including consultations, concept development, procurement, project management, and any associated expenses.
B. Payment Schedule
|
Payment Milestone |
Amount Due |
Due Date |
|---|---|---|
|
Retainer Fee |
[$3,000] |
Upon Signing |
|
Design Concepts Approval |
[$4,000] |
July 1, 2050 |
|
FF&E Procurement |
[$5,000] |
August 1, 2050 |
|
Project Completion |
[$3,000] |
September 1, 2050 |
C. Payment Details
-
Retainer Fee: Upon signing this contract, the Client agrees to pay a retainer fee of [$3,000] to secure the services of the Designer. This retainer fee serves as an initial payment towards the total cost of the project and is non-refundable.
-
Design Concepts Approval: Once the initial design concepts are presented to the Client and approved, a payment of [$4,000] is due on or before July 1, 2050. This payment milestone marks the Client's commitment to the proposed design direction and initiates the procurement phase of the project.
-
FF&E Procurement: Upon approval of the design concepts, the Client agrees to make a payment of [$5,000] towards the procurement of furniture, fixtures, and equipment (FF&E) by August 1, 2050. This payment facilitates the purchase and acquisition of materials necessary for the implementation of the design plan.
-
Project Completion: The final payment of [$3,000] is due upon project completion on September 1, 2050. This payment milestone signifies the successful execution and delivery of the interior design project to the Client's satisfaction. Upon receipt of the final payment, any outstanding balances will be settled, and the project will be considered officially closed.
V. Client Responsibilities
A. Access to Property
-
Client agrees to provide Designer with access to the property during scheduled appointments and installation days. Client will ensure that the property is accessible and safe for Designer and any subcontractors or vendors involved in the project.
B. Communication
-
Client agrees to promptly respond to communication from Designer regarding project decisions and approvals. Client will maintain open and clear communication channels with Designer throughout the duration of the project, providing timely feedback and responses to facilitate efficient progress.
C. Approval Process
-
Client will review and approve design concepts, materials, and any proposed changes within a reasonable timeframe to avoid delays in the project schedule. Timely approval from the Client is essential for the smooth progression of the design and implementation phases.
VI. Designer Responsibilities
A. Professionalism
-
Designer agrees to conduct themselves in a professional manner at all times when interacting with the Client and other project stakeholders. This includes maintaining confidentiality, respecting the Client's privacy, and upholding ethical standards in all aspects of the design process.
B. Timeliness
-
Designer commits to adhering to the agreed-upon project timeline and milestone deadlines. This includes delivering design proposals, procurement schedules, and project updates in a timely manner to keep the Client informed of progress and ensure project milestones are met.
C. Quality Assurance
-
Designer will ensure that all design solutions and materials selected meet the highest standards of quality, functionality, and aesthetic appeal. Designer will exercise diligence in the selection of furniture, fixtures, and equipment (FF&E), ensuring they align with the Client's preferences, budget constraints, and project requirements.
D. Documentation
-
Designer will maintain accurate records of all project-related communications, agreements, approvals, and expenses. This includes keeping detailed project files, contracts, invoices, and receipts organized and accessible for reference throughout the duration of the project and beyond.
E. Project Coordination
-
Designer will oversee all aspects of project coordination, including liaising with contractors, vendors, and other service providers to ensure seamless execution of the design plan. Designer will schedule and supervise site visits, installations, and inspections to monitor progress and address any issues promptly.
VII. Termination Clause
A. Early Termination
-
Either party may terminate this contract with written notice if the other party fails to fulfill their obligations outlined in this agreement. In the event of termination, the terminating party shall provide written notice specifying the reasons for termination and the effective date of termination.
B. Refund Policy
-
In the event of early termination initiated by the Client, any payments made by the Client will be refunded on a prorated basis, minus expenses incurred by the Designer up to the termination date. The prorated refund amount will be calculated based on the percentage of completed work versus the total project scope outlined in this contract.
-
If termination is initiated by the Designer due to the Client's failure to fulfill their obligations or breach of contract, any payments made by the Client will not be refundable. The Designer reserves the right to retain all payments received as compensation for work completed, expenses incurred, and damages resulting from the termination of the contract.
VIII. Legalities
A. Governing Law
-
This contract shall be governed by the laws of [Jurisdiction]. Any disputes arising from or relating to this contract shall be resolved in accordance with the laws of [Jurisdiction], and the parties hereby submit to the exclusive jurisdiction of the courts of [Jurisdiction] for the resolution of any such disputes.
B. Dispute Resolution
-
Any disputes arising from this contract shall be resolved through mediation or arbitration in accordance with the rules and procedures of [Arbitration Institution/Association]. Both parties agree to participate in good faith in the mediation or arbitration process and to abide by any decision or award rendered by the mediator or arbitrator.
-
If mediation or arbitration fails to resolve the dispute, either party may seek relief through litigation in the courts of [Jurisdiction]. However, the parties agree to exhaust all alternative dispute resolution methods before resorting to litigation. Each party shall bear their own costs and expenses incurred in any dispute resolution proceedings, including legal fees and expenses.
IX. Indemnification
A. Designer's Indemnification
-
The Designer agrees to indemnify and hold harmless the Client from and against any claims, damages, losses, liabilities, and expenses, including reasonable attorney's fees, arising out of or related to the Designer's performance of the services under this contract, except to the extent caused by the Client's negligence or misconduct.
B. Client's Indemnification
-
The Client agrees to indemnify and hold harmless the Designer from and against any claims, damages, losses, liabilities, and expenses, including reasonable attorney's fees, arising out of or related to the Client's breach of this contract or any negligent or willful acts or omissions of the Client or its agents.
X. Confidentiality
A. Confidential Information
-
Both parties agree to maintain the confidentiality of any proprietary or confidential information disclosed during the course of the project. This includes, but is not limited to, design concepts, financial information, trade secrets, and any other sensitive information shared between the parties.
B. Non-Disclosure
-
The Designer and the Client agree not to disclose any confidential information to third parties without the prior written consent of the disclosing party, except as required by law or court order. This obligation of confidentiality shall survive the termination of this contract.
-
Each party shall take reasonable measures to protect the confidentiality of the other party's confidential information, including implementing appropriate security measures and restricting access to confidential information on a need-to-know basis.
C. Exceptions
-
The obligations of confidentiality shall not apply to any information that:
-
Was already known to the receiving party prior to disclosure by the disclosing party.
-
Becomes publicly available through no fault of the receiving party.
-
Is independently developed by the receiving party without reference to the disclosing party's confidential information.
-
Is rightfully received from a third party without restrictions on disclosure.
-
D. Survival
-
The provisions of this confidentiality clause shall survive the termination or expiration of this contract and shall remain in full force and effect indefinitely.
XI. Amendment and Modification
A. Amendment
-
This contract may be amended or modified only by a written instrument signed by both parties. Any amendments or modifications to this contract shall be deemed effective only upon mutual agreement and execution by both the Client and the Designer.
B. Notice
-
Any notices, requests, or communications regarding the proposed amendment or modification of this contract shall be delivered in writing and sent to the respective parties' addresses as specified in this contract. Notices shall be deemed effective upon receipt by the intended recipient.
C. Waiver
-
The failure of either party to enforce any provision of this contract or to exercise any right or remedy hereunder shall not constitute a waiver of such provision, right, or remedy. Any waiver of any provision of this contract shall be effective only if it is in writing and signed by the waiving party.
D. Severability
-
If any provision of this contract is held to be invalid, illegal, or unenforceable by a court of competent jurisdiction, such provision shall be severed from this contract, and the remaining provisions shall remain in full force and effect to the fullest extent permitted by law.
E. Entire Agreement
-
This contract constitutes the entire agreement between the parties concerning the subject matter hereof and supersedes all prior and contemporaneous agreements, negotiations, understandings, and communications, whether written or oral, between the parties relating to such subject matter.
F. Execution
-
This contract may be executed in counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument. Execution of this contract may be by electronic signature or other electronic means, which shall have the same legal effect as manual signature.
XII. Signature
A. Execution
This contract shall be deemed executed and binding upon the parties upon the signature of both the Client and the Designer.
B. Client Signature
[Client Name]
[Date of Client Signature]
[Your Name]
[Date of Your Signature]
[Witness Name]
[Date of Witness Signature]
C. Acknowledgment
-
By signing below, the Client and the Designer acknowledge that they have read, understood, and agreed to all the terms and conditions set forth in this contract. Each party hereby represents and warrants that they have full authority to enter into this contract and to bind their respective entities to its terms.
-
This contract may be executed in counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument. Execution of this contract may be by electronic signature or other electronic means, which shall have the same legal effect as manual signature.
